Terms of Service

1. Acceptance of Terms

By accessing or using our website and services, you agree to comply with and be bound by these Terms of Service and our Privacy Policy. If you do not agree with any part of these terms, you may not access our website or use our services.

These Terms apply to all visitors, users, clients, and others who access or use our services.

2. Company Information

Belaya Seledka
Business Address: 1425 Rene-Levesque Blvd W, Suite 3200, Montreal, QC H3G 1T7, Canada
Phone: +1 (514) 555-0187
Email: [email protected]

Belaya Seledka is a professional interior design firm specializing in luxury residential properties across Canada.

3. Services Description

Belaya Seledka provides luxury interior design services including:

• Complete interior design and renovation consultation
• Luxury property staging for real estate sales
• Custom millwork and built-in design
• Space planning and layout optimization
• Material selection and procurement
• Project management and coordination
• Art curation and placement services
• Lighting design and installation

All services are subject to individual service agreements and project contracts.

4. Website Use

4.1 Permitted Use

You may use our website for:

• Viewing our portfolio and services
• Reading our blog and design insights
• Contacting us for inquiries and consultations
• Subscribing to our newsletter
• Sharing our content on social media platforms

4.2 Prohibited Use

You may not use our website to:

• Violate any applicable laws or regulations
• Transmit harmful, offensive, or illegal content
• Attempt to gain unauthorized access to our systems
• Copy, reproduce, or distribute our content without permission
• Use our website for commercial purposes without authorization
• Interfere with the proper functioning of the website

5. Service Agreements

5.1 Contract Formation

Design services are provided under separate written contracts. These Terms of Service supplement but do not replace individual service agreements.

5.2 Consultation Process

Initial consultations are provided at no charge for qualified projects. Detailed proposals and project contracts will specify:

• Scope of work and deliverables
• Project timeline and milestones
• Fee structure and payment terms
• Client responsibilities and requirements
• Terms specific to the project

5.3 Project Changes

Changes to approved designs or project scope must be documented in writing and may result in additional fees and timeline adjustments.

6. Payment Terms

6.1 Fees and Pricing

Our fees are based on project scope, complexity, and timeline. All pricing is provided in Canadian dollars unless otherwise specified.

6.2 Payment Schedule

Payment terms are specified in individual project contracts. Generally:

• Design fees are due in installments based on project milestones
• Product purchases require deposits before ordering
• Final payment is due upon project completion
• Late payments may incur interest charges as specified in contracts

6.3 Cancellation Policy

Cancellation terms are specified in individual service agreements. Generally, work completed to the date of cancellation will be charged according to the agreed fee structure.

7. Intellectual Property

7.1 Our Content

All content on this website, including designs, images, text, logos, and graphics, is the property of Belaya Seledka and is protected by Canadian and international copyright laws.

7.2 Design Work

Design concepts, plans, and specifications created for clients remain the intellectual property of Belaya Seledka unless otherwise specified in writing. Clients receive usage rights for their specific project.

7.3 Portfolio Use

We reserve the right to photograph completed projects and use images for marketing purposes unless specifically restricted by contract.

8. Client Responsibilities

Clients are responsible for:

• Providing accurate project information and requirements
• Obtaining necessary permits and approvals
• Ensuring site access and safety compliance
• Timely payment according to contract terms
• Protecting installed furnishings and finishes
• Coordinating with other contractors and professionals
• Making timely decisions to avoid project delays

9. Warranties and Disclaimers

9.1 Service Warranty

We warrant that our services will be performed in a professional manner consistent with industry standards. Any warranty claims must be made in writing within 30 days of project completion.

9.2 Product Warranties

Products are covered by manufacturer warranties. We do not provide additional warranties on third-party products beyond those offered by manufacturers.

9.3 Disclaimers

TO THE MAXIMUM EXTENT PERMITTED BY LAW, OUR SERVICES ARE PROVIDED "AS IS" WITHOUT WARRANTIES OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.

10. Limitation of Liability

TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW:

• Our total liability for any claim shall not exceed the amount paid for the specific service giving rise to the claim
• We shall not be liable for indirect, incidental, special, or consequential damages
• We are not liable for delays caused by circumstances beyond our reasonable control
• Claims must be brought within one year of the completion of services

11. Force Majeure

We shall not be liable for delays or failures in performance resulting from circumstances beyond our reasonable control, including:

• Natural disasters or extreme weather conditions
• Government actions or regulatory changes
• Labor disputes or supply chain disruptions
• Pandemics or public health emergencies
• Acts of terrorism or civil unrest

12. Privacy and Data Protection

Our collection and use of personal information is governed by our Privacy Policy, which is incorporated by reference into these Terms. Please review our Privacy Policy to understand our data practices.

13. Dispute Resolution

13.1 Governing Law

These Terms shall be governed by and construed in accordance with the laws of the Province of Quebec and the federal laws of Canada applicable therein.

13.2 Jurisdiction

Any disputes arising from these Terms or our services shall be subject to the exclusive jurisdiction of the courts of Quebec, Canada.

13.3 Mediation

Before pursuing legal action, parties agree to attempt resolution through good faith negotiations and, if necessary, mediation through a mutually agreed mediator.

14. Termination

We may terminate or suspend your access to our website immediately, without prior notice, for conduct that we believe violates these Terms or is harmful to other users, us, or third parties.

Upon termination, your right to use our website ceases immediately. All provisions of these Terms that by their nature should survive termination shall survive.

15. Modifications to Terms

We reserve the right to modify these Terms at any time. Changes will be effective immediately upon posting on our website. Your continued use of our website or services after changes are posted constitutes acceptance of the modified Terms.

Material changes will be communicated through:

• Email notification to registered users
• Prominent notice on our website
• Updated "last modified" date on this page

16. Severability

If any provision of these Terms is found to be unenforceable or invalid, that provision will be limited or eliminated to the minimum extent necessary so that these Terms will otherwise remain in full force and effect.

17. Contact Information

For questions about these Terms of Service, please contact us: